24D-041 (6) BP-2023-1384
185 PROSPECT ST COMMONWEALTH OF MASSACHUSETTS
Map:Block:Lot:
24D-041-001 CITY OF NORTHAMPTON
Permit: Exterior Res
PERSONS CONTRACTING WITH UNREGISTERED CONTRACTORS
DO NOT HAVE ACCESS TO THE GUARANTY FUND (MGL c.142A)
BUILDING PERMIT
Permit# BP-2023-1384 PERMISSION IS HEREBY GRANTED TO:
Project# ROOF 2023 Contractor: License:
Est. Cost: 16558 LA ROOFING LLC 106268
Const.Class: Exp.Date:02/03/2024
Use Group: Owner: K WHERRY, JOSHUA R. &CANDACE
Lot Size (sq.ft.)
Zoning: URB Applicant: LA ROOFING LLC
Applicant Address Phone: Insurance:
670 NEWFIELD ST UNITC (860)877-3006 BAK-77391-2
MIDDLETOWN, CT 06457
ISSUED ON: 10/12/2023
TO PERFORM THE FOLLOWING WORK:
STRIP AND REROOF
POST THIS CARD SO IT IS VISIBLE FROM THE STREET
Inspector of Plumbing Inspector of Wiring D.P.W. Building Inspector
Underground: Service: Meter: Footings:
Rough: Rough: House # Foundation:
Final: Final: Final: Rough Frame:
Gas: Fire Department Driveway Final: Fireplace/Chimney:
Rough: Oil: Insulation:
Smoke: Final:
THIS PERMIT MAY BE REVOKED BY THE CITY OF NORTHAMPTON UPON VIOLATION OF
ANY OF ITS RULES AND REGULATIONS.
Signature:
• • >2 . 3-)PiT
Fees Paid: $115.00
212 Main Street,Phone(413)587-1240,Fax:(413)587-1272
Office of the Building Commissioner
11€c /i,
o FO
3 •h r11+-Y' er -
sl., The Commonwealth of Mas chuS8t?.
_ Board of Building Regulations an n F R
Vi.
Massachusetts State Building Code, 780 1 roN iNSp UN IPALITY
USE
Building Permit Application To Construct,Repair,Renovate Or 404,S Rev sed Mar 2011
One-or Two-Family Dwelling °
This S li n For Official Use Only
Building ermit Number: $49'0"3 /3 y Date A lied:
et.)11—N/Z / e-o-zoz3
Building Official(Print Name) Signature Date
SECTION 1:SITE INFORMATION
1.1 i o�p�t�dd� M.
1.2 Assessors Map&Parcel Numbers
1.1 a Is this an accepted street?yes no Map Number Parcel Number
1.3 Zoning Information: 1.4 Property Dimensions:
Zoning District Proposed Use Lot Area(sq ft) Frontage(ft)
1.5 Building Setbacks(ft)
Front Yard Side Yards Rear Yard
Required Provided Required Provided Required . Provided
1.6 Water Supply:(M.G.L c.40,§54) 1.7 Flood Zone Information: 1.8 Sewage Disposal System:
Public 0 Private 0 Zone: _ Outside Flood Zone? Municipal 0 On site disposal system ❑
Check if yes❑
SECTION 2: PROPERTY OWNERSHIP'
2.1,$wner'of Record:
J Met WIAvel31404. 414-T-Evw 1 rAk olb,o
Name(Print) City,State,ZIP
No.and Street Telephone Email Address
SECTION 3:DESCRIPTION OF PROPOSED WORK2(check all that apply)
New Construction 0 Existing Building 0 Owner-Occupied 0 Repairs(s) 0 Alteration(s) 0 Addition 0
Demolition 0 Accessory Bldg. ❑ Number of Units Other 0 Specify:__
Brief Description of Proposed Work2:
SECTION 4:ESTIMATED CONSTRUCTION COSTS
Item Estimated Costs: Official Use Only
(Labor and Materials)
1.Building $ 1. Building Permit Fee: $ Indicate how fee is determined:
❑ Standard City/Town Application Fee
2.Electrical $ ❑Total Project Costa(Item 6)x multiplier x
3.Plumbing $ 2. Other Fees: $
4.Mechanical (HVAC) $ List:
5. Mechanical (Fire $
Suppression) Total All Fees: $ x
�r 4 Check No.31a(theck Amount: PH U Cash Amount:
6.Total Project Cost: $ l 1/ ❑Paid in Full 0 Outstanding Balance Due:
SECTION 5: CONSTRUCTION SERVICES
5.1 Construction Supervisor License(CSL) I w M A f l036
41\61C514k4ViiiVIL License Number Expiration Date
Name of CSL Holder
i1 I\ '\ k List CSL Type(see below)
`�and
�s trrejet� I. �f/� Type Description
1 VUYI/('7Y t'K. (VI 61 l U Unrestricted(Buildings up to 35,000 Cu.ft.)
R Restricted 1&2 Family Dwelling
Ci /Town,State,ZIP M Masonry
RC Roofing Covering
WS Window and Siding
�1„`�_Ia IIM•�, SF Solid Fuelo Burning Appliances
e'rp/j T( fi �,��. (�0'YYl/ I Insulation
Tel hone ' EmaiLktddress D Demolition
5.2 el74,41Home Improvement Contractor(HIC) .�'t y��� ik Jy
\ 11✓ HIC Registration Number xpiration'' Date
HI I egistran me
• UAW (..' IO 01 • Yl� •��t:t 1 '
1�(qt d t t ',�,tN wevksi
$�h fil,
J Emai d ess
City/Town,State,ZIPI Telephone
SECTION 6:WORKERS'COMPENSATION INSURANCE AFFIDAVIT(M.G.L.c.152.§ 25C(6))
Workers Compensation Insurance affidavit must be completed and submitted with this application. Failure to provide
this affidavit will result in the denial of the Issuance o the building permit.
Signed Affidavit Attached? Yes No .0
SECTION 7a:OWNER AUTHORIZATION TO BE COMPLETED WHEN
OWNER'S AGENT OR CONTRACTOR APPLIES FOR BUILDING PERMIT
I,as Owner of the subject property,hereby authorize
to act on my behalf,in all matters relative to work authorized by this building permit application.
Print Owner's Name(Electronic Signature) Date
SECTION 7b:OWNER'OR AUTHORIZED AGENT DECLARATION
By entering my name below, I hereby attest under the pains and penalties of perjury that all of the information
contain� 'n this application is true and accur st of my knowledge and understanding.
V►I oCL iv 2123
Print Owner's or Auth razed Age s Name(Electronic Signature) Date
NOTES:
1. An Owner who obtains a building permit to do his/her own work,or an owner who hires an unregistered contractor
(not registered in the Home Improvement Contractor(HIC)Program),will not have access to the arbitration
program or guaranty fund under M.G.L.c. 142A.Other important information on the HIC Program can be found at
www.mass.gov/oca Information on the Construction Supervisor License can be found at www.mass.gov/dps
2. When substantial work is planned,provide the information below:
Total floor area(sq.ft.) (including garage,finished basement/attics,decks or porch)
Gross living area(sq. ft.) Habitable room count
Number of fireplaces Number of bedrooms
Number of bathrooms Number of half/baths
Type of heating system Number of decks/porches
Type of cooling system Enclosed Open __
3. "Total Project Square Footage"may be substituted for"Total Project Cost"
City of Northampton
Sys • 'lc,
Massachusetts
_ DEPARTMENT OF BUILDING INSPECTIONS
212 Main Street • Municipal Building yeti P�
Northampton, MA 01060 sS,' 3 °'
CONSTRUCTION DEBRIS AFFIDAVIT
(FOR ALL DEMOLITION AND RENOVATION PROJECTS)
In accordance of the provisions of MGL c 40, S54, a condition of Building Permit
Number is that all debris resulting from this work shall be disposed of in a
properly licensed waste disposal facility, as defined by MGL c 111, S 150A.
The debris will be disposed of in:
AditIOLLocation of Facility: \Mk-
O�v
l )
The debris will be transported by:
�- \ YY1
Name of Hauler: \ , a'`I \* VVAA (
Signature of Applicant: Date: tv(�I23
The Commonwealth of Massachusetts
kF Department of Industrial Accidents
r
-- ;: 1 Congress Street,Suite 100
`�,f Boston, MA 02114-2017
www.mass.go)/dia
in kers' Compensation Insurance Afi das it: BuikIerai('ontractors;L 1ectriciansrPlumbers.
11)Ht. EII.E:l)KITH iHkPEH%IIif INC At IHOWI►.
Applicant Information i Please Print Leiibh
Name. IBusaicss Organization Individual►: Yi 1
Address:._ lir(b VVA,AA(1& •
City/State Zip: Y ilkikk 'i (v1 �kkq Phone ::: Y!kO'VI 1- y
Are,es resplriser'.'(heel.the appropriate t os: I spent project(required)
I I am a cniplosis wAh Jit cngrloyee%ttull and.r pan-time 1• 7• 0 Noss construction
:.a I an a..ile prrrptxtur or partnrr.hip and hale no emplo .a. wor►mg for nit in B. O Remodeling
am..rpacit► (Nu workers'comp.unurante required I
9. 0 Demolition
t.LJ I ant a him loner doing all work myiell.[No w:hears'comp-trtsuranec myuneel.I"
IUEl Building addition
4.❑I am a Barrio ou tie/and w ill he hiring Lonna.tots to conduct all weal on tin pioperI . 1 w dl
ensure that all sontraetun either lime wrnksn co m peri.:mon tsr.uran...a are vile I I a Electrical repairs or additions
pr.gsttdon with no cmploscen
12.0 Plumbing repairs or adtitions
SCi I am a general.untractor and I la%c hind the sob-auntractots listed on the atta.heel%heel
Mo..sob-sontracton lase.cmplo cis And Rase wagers ♦sprig.imuraM. 13 repairs
.Q IA are a eo �atiun and it..ottieh-n Imes c onto iwd thou right of ete 14.❑Otltet
d ---*p. mptii n�r Wit.c
1 .!.;114i.and we hasc no employees.I\o%mien'etanp irutaan..required I
'Aayappti..mt that shwa.hot n1 must also till out the section below showing then sour►mT.'compensation poi lc!, information
+Iioeicown.r.who,uhinil this atlidas it ind,.aung t1ii an.doing all work and then hue outside contra.t.as nrini.uhinit a nc4 at:ides it Indis:ttmg%tech
!Comm:tots that chc.I.Mi.ties must alti.tied an additional.hcct show inc the name of the soh-contractor.and,tat.whether or not Chow entities have
criploscc, It[Mc.uh-untractiasbass:cirtr otcc..ttte% must proud..1 thin sorkcr.'.snnp pubes number
I am an employer that is providing workers'compensation insurance for tn,•employees. Below is the policy and job site
information 1'
Insurance Company Name: I�a, .,L u�r'n ,�"r`a' az_
pd.!. s or Selt=ms.Lie. �e' 1 l9)R 1 �2 Expiration Date: iSillk
Job Site Address: ! ' khv 1b 1+ V\(' \km/ ,� rf City Stale-Zip: YYI/T
Attach a cop, of the wor �kers'compensation policy declaration page(showing the policy number and expiration dale).
Failure to secure cuserage as required under MCA.c. 152.,25A is a criminal s iolation punishable by a tine up to S I.500.(Xt
and'or one-}ear imprisonment.as sell as etcil penalties in the Corm of a STOP WORK ORDER and a tine of up to S250.00 a
day against the s tolator. A copy of this statement may be t'onvarded to the()Bice of Ins esttgations of the DiA for insurance
co%erage%entication.
/do hereby certify r Jr e pains - s rrfperjurr that the information provided above is true and correct.
Signature 1)...::: t bl -12
Phone:: (g.(e) $T1'3
Official use only. Do not write in this urea.to be t ompleled by city or town official
('itr, or Town: Permit/License ti
Issuing Authorit (circle one):
I. Board of Health 2. Building Department 3.City/Town Clerk 4.Electrical Inspector 5. Plumbing Inspector
b.Other
Contact Person: Phone St:
The Commonwealth of Massachusetts
i` Department of Industrial Accidents
_ AMMO
_a moo..� 1 Congress Street.Suite 100
=:�ti! , Boston. MA 02114-2017
.__ = www mass.go►•/dia
- 11utkers'('onipensation Insurance Adidas it: Builders/('ontractor. lectricians /'lumber+.
1O HE I liii)11 I I'll I III_PI R%11 I'i INC Al•111ORI 1 1.
Applicant Information �rllY' ' - Please Print Lriit►It,
Name 4Hustncs,t►r.•antrjnon Ind-stduati �
N�
Address: WI� Ct . \AA vLtom'J
C'ityrStatelZip.I(`(\Illtl.lt h W1' ( LT Cleta Phone#: 61eb 'q)17'' b�o
An yak cmpbi.cr.!(beck for appruprtatc bus:
,..
Type of project(required)
I. 1 atn a enq.loser*rib crrgdosecs I full and or part-time).* 7. 0 Voss construction
_0 1 am a ok pnrprtcter or partnership and ha.c no empleis.x%minis for me m K. O Remodeling
am.apaciit t\u w.ut4'n'comp.rnsurane required I
9. 0 Demolition
1 1 arts a h.onastuti.n dot;all sorb mssell.I\u 14t+ttt.1a'comp ,n.urutcc nyutt.d t'
1 0 a Building addition
4 0 1 am )sm a - vu n.-r and*ill he hning contractors to conduct all ss ink on rm p,uperty. 1 cad/
ensure that all.unttactors ciders hate 1.1NLett" m/ens lt,On insurance or am sole I I a E le tnclll repairs or additions
pt.opnetots auk rm.,err11/10:1ees
12.0 Plumbing repairs ui additions
S0 I am a general Luntr:etot and I has hind the,uh-contractors listed on the attached sheet
13.❑Root repairs
!hex sub-..infractors has.employees and has e*takers".oinp.insurance
A D tc are a cosrp<ration and its officers has t e right
re ised then eht of exemption per Mt c I 4 ❑0thei
l:(_s.;It4i.and ac fuse no uttphesces I\o*takers'etmtp Irlslaunee required l
•Arr.applicant that.h.a-I.s boa al muse also till out the section below show nig then ss.a►crs'compensation popes mtarnatten
'Hon ,Mars 1,60 submit this atlwlas it indicating then arc doing ail stork and then here outside contra.9.r.mint submit a new at:idas it ind utmg,u.h
:l onnactots that chc.L this hos must att...bed an ald,horul sheet shoecint the name of(lie soh-centhact.rs and.tare w Tether or not!how entities here
engdusce, It the suh-..mtra.t n,lust crrgslo}ees.they must pros ode thtar aurkcrsswmLs poke!.number
t am an employer that is providing warders'compensation insurance for my einpinrees. Below is the policy and job site
information. I,
Insurance Company Name: t Q6IV k5t^/Lf/j�
Pokey =or Self-ins. Lie.»:�� '1T611.Z- ✓ Expiration Date. 31 i. 41,�
Job Site Address:__ k V -- ,(�jA. 0-"11AALAAAAO1'\t City State Zip: „4Ar
Attach a copy of the ss orkrrs'compensation policy declaration page(shoving the policy number and expiration date).
Failure to secure coverage as required under JMCiL c. 152,§25A is a criminal violation punishable by a tine up to 51.5(X).0()
and or one-year impnson ent.as%sell as cisil penalties in the form of a STOP WORK ORDER and a tine of up to 5250.00 a
day against the s itilator. A copy of this statement nwy he tons aided to the Office of Insestigations of the DIA Iisr insurance
cos crage s cntication.
I do hereby certify a hi call ties at perjury that the information provider/above is true and correct.
Si•nature. Date. t 112
Phone - $4.0 2)Z7-
tmit iul use anll. Da not write in this area.to be completed by cite or town official
( it% err limn: Pernlill.icense$4
issuing Authority (circle one):
I. Hoard of Health 2.Buikling Department 3.City r1onn Clerk 4. Electrical Inspector 5. Plumbing Inspector
Ii. Other
( outset Person: Phone a:
ACc aCERTIFICATE OF LIABILITY INSURANCE DATE(MM/DDIYYYY)
h.------ 03/13/2023
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED
REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER.
IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed.
If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on
this certificate does not confer rights to the certificate holder in lieu of such endorsement(s).
PRODUCER CONTNAME:
MONA LISA GOULART
1 OAK INSURANCE AGENCY LLC PHONE
(A/o No,q,.ty; (203)632.5004 F ,Na):(203)6324000
167 MAPLE ST ADDRESS: MG a@1 OAKINSURANCE.COM
Naugatuck, CT 06770 INSURER(S)AFFORDING COVERAGE MAC 0
INSURER A; CRUM&FOSTER SPECIALTY INSURANCE CO__
INSURED INSURERS: HARTFORD UNDERWRITERS INS CO
LA ROOFING LLC INSURER C:
40 HILLSIDE AVE INSURER 0:
PLANTSVILLE, CT 06479 INSURERS:
INSURER F:
COVERAGES CERTIFICATE NUMBER: 00000224-20209 REVISION NUMBER: 8
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO.THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
ILTR TYPE OP INSURANCE ADOL SUBR POLICY EFF POLICY EXP
DM WVO POLICY NUMBER (MM/DD/YYYY) (MMIDDIYYYYI LIMITS
A X COMMERCIAL GENERAL UABILI Y Y BAK-77391-2 03/15/2023 03/15/2024 EACH OCCURRENCE $ 1,000,000
DAMAGE TO RENTED
1 CLAIMS-MADE X OCCUR PREMISES(Ea occurrence) $
MED EXP(Any one person) $ 5,000
I PERSONAL&ADV INJURY $ 1,000,000
GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 2,000,000
X POLICY FI JeE LOC PRODUCTS-COMP/OP AGO $ 2,000,000
I OTHER: $
AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT $
--— (Ea accident)
ANY AUTO _ BODILY INJURY(Per person) $
AWNED SCHEDULED BODILYINJURY(Peraccident $
AUTOS ONLY AUTOS )
HIRED NON-OWNED PROPERTY DAMAGE
AUTOS ONLY ___. AUTOS ONLY (Per accident) $
$
I UMBRELLA LIAR I
— OCCUR EACH OCCURRENCE $
I EXCESSLIAS CLAIMS-MADE AGGREGATE $
DED RETENTIONS $
B AND EMPLOYERS WORKERS �LIABIION
UTY 6S6OUB-5R96820-0.22 03/13/2023 03/13/2024 X STATUTEOTFI-
ER
Y/N E.L.EACH ACCIDENT $ 100 000
OFFICER/MEMBER EXCLUDED?PROPRIETOR/PARTNER/EXECUTIVE Y N/A r
(t RIPMandatory in NH) 1 E.L.DISEASE-EA EMPLOYEE $ 100,000
DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ 500,000
DESCRIPTION OF OPERATIONS I LOCATIONS/VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached if more apace Is required)
CERTIFICATE HOLDER CANCELLATION
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
LA ROOFING LLC THE EXPIRATION DATE THEREOF,NOTICE WILL BE DELIVERED IN
ACCORDANCE WITH THE POLICY PROVISIONS.
LUIS POMAQUIZA
PLANTSVILLE, CT 06479 AUTHORIZED REPRESENTATIVE
I �, (MLG)
.`V'1988-2015 ACORD CORPORATION. All rights reserved.
ACORD 25(2016/03) The ACORD name and logo are registered Marks of ACORD Printed by MLG on 03/13/2023 at 02:30PM
Architectural Shingle [Color and style Closest to Match Existing: ONYX BLACK]with Surenail Technology and
StreakGuardTM 25-year Algae Resistance Limited Warranty. Fasten with 1 1/2"galvanized roofing nails, using 6
nails per shingle. Code compliant for high winds up to 130 mph.
10. Reflash chimney with aluminum step flashing, and lead counter-flashing.
*Additional Details*
11. Remove existing ridge caps and ridge vents on main house. Ensure that shingles are not blocking the ridge
opening, and cut any that are to allow proper airflow from ridge. Install Owens Corning Ventsure 4-Foot Strip ridge
vents on main house roofs.
12. Install Owens Corning Hip and Ridge shingles to all ridges of roof.
13. Remove first course of existing shingles on eaves of main house roof, and remove drip edge. Install new F5
Aluminum Drip Edge (4"overhang)to sections of eave where gutter is pitched father down, to prevent water from
going behind gutter.
14. Remove shingles on lower main house roof down to the wood decking.
15. Install new ice/water barrier directly around chimney.
16. Install new aluminum step-flashing and Lead Counter-Flashing on chimney.
17. Install new Architectural shingles over newly installed drip edge and directly around chimney, color and style
closest to match existing.
18. Remove shingles and cut aluminum siding where all roof sections meet walls of house, 4" up.
19. Install ice/water barrier directly on wood decking and on exposed wood wall.
20. Install new PVC Composite White Fascia Board on all roof-to-wall sections, with new Z-Metal Flashing to prevent
water from going behind siding.
21. Install new architectural shingles, color and style closest to match existing on flashing areas.
EPDM:
22. Remove existing shingles on flat roof section in front of house down to wood decking.
23. Install new fiber/insulation board over wood decking on flat roof section.
24. Secure fiber board to decking with exterior galvanized plates and screws.
25. Install new Rubber EPDM roofing using EPDM Bonding Adhesive.
26. RAKE FASCIA METAL &J-CHANNEL-Wrap existing fascia metal with new fascia metal to ensure that
the fascia metal overlaps the existing aluminum J-Channel on main house roof, back side only-in order to
prevent water from going behind siding. Additional cost of$648 INCLUDED in total below.
Clean Up
27. Clean up entire area daily-raking yards, passing magnet sweep over entire surrounding area of home where
work has been performed and cleaning all debris from gutters-to leave like new when completed.
- Price reflects labor, materials and dump fees. Permit fees are additional and charged by the city/town. This fee
will be added to the final invoice LA Roofing LLC agrees to warranty the workmanship for 25 years. LA Roofing
will register completed roof with Owens Corning for their extended warranty once the project is paid in full.
Shingle Roof Sections (including lower main house roof), Ridge Vent Replacement, Drip Edge Installation on
Main House Bundle: $9,400
ROOF-TO-WALL FLASHING COMPOSITE: $3,210
EPDM RUBBER ROOF FRONT PORCH: $3,300
FASCIA METAL INSTALLATION SPECIFIED SECTIONS: $648
We propose hereby to finish material and labor completed in accordance with the above specification for the sum of:
$16,558 Dollars
Payment to be made as follows:
50% - $8,279 Payment required prior to start of job
BALANCE DUE UPON COMPLETION OF WORK
HOME IMPROVEMENT CONTRACT
AGREEMENT
This AGREEMENT is between: LA Roofing LLC located at 670 Newfield St. Unit C., Middletown,
CT 06457; Phone: (860) 877-3006 (hereinafter called "Contractor"). and
Josh Wherry (hereinafter called "Owner")on this 08/29/2023
In exchange for the mutual terms and conditions set forth, Owner and Contractor agrees to the following:
1. Owner has been verbally advised rights of cancellation.
2. Owner has received two copies of"Notice of Cancellation".
Typically, upon acceptance and receipt of down paymen , 9 -
the Production Manager will reach out within 2 (two)
elasisetuithetty
weeks to schedule the project, which gives LA Roofing
time to apply for the building permit and order materials.
Upon signing this proposal, the anticipated start date is -d
between 09/12/2023 and 09/19/2023-weather Due to unforeseeable increases in material costs,the price in
this proposal is guaranteed
permitting-with an anticipated completion date of for 15 days ONLY
09/19/2023. Typically, roofing projects are completed
within one day, but this also depends on the size and
complexity of the roof.
-All materials are guaranteed to be as specified. Authorized Signature:
-All work is to be completed in a workmanlike manner and
compliant with state building code. Afaelle pin6a,uQutt
-A twenty five-year workmanship warranty is provided.
-Any unsound decking will be replaced at an additional
08/29/2023
charge.
-All agreements are contingent upon delays beyond our Date. 08/29/2023
control.
Terms and Conditions:
1.Written Change Order for Additions and Changes to Work:
Changes to the Work in this contract can only be made upon signing a written change order signed by the
Owner. Payment in full is required for modifications upon completion of Work.
2. Cancellation after 3 business days:
The parties agree that this contract is binding to Owner after the three-business day cancellation period.
Owner understands and acknowledges that Owner's failure to cancel within the period is consent to a
binding contract and Contractor incurs associated costs of labor and materials in order to begin work in
reliance of Owner's conduct. Owner acknowledges that cancellation after the three business day cancellation
period would be a breach of the parties' agreement and agrees to liquidated damages of 25% of the contract
price or the entire deposit,whichever is greater
3. Failure to Make Scheduled Payment for Ongoing Work by Contractor:
If Owner fails to pay the amounts due for Work performed, Owner agrees to a default rate of 1.5% per month
of the amount due as late fees. Owner also understands and agrees that in the event of non-payment,
Contractor my file a mechanic's lien on the demised property. In addition, Owner agrees that if a lawsuit is
brought by Contractor for debts owing under this Contract, Owner is liable also for payment of Contractor's
attorneys fees, costs of collection, court costs and interest. In the event, Owner fails to pay the amounts due
after work has begun, Owner hereby agrees that Contractor may stop work and agrees to grant Contractor a
license to enter Owner's property to collect Contractors tools and unpaid materials. In that event,Owner
waives all legal claims of trespass against Contractor for this purpose. Owner further agrees that in the event
that Owner has failed to make payment for over thirty(30) days after work has begun, Contractor, at its sole
discretion, may terminate this contract on the grounds of breach by Owner and bring a legal action for
nonpayment.
4. Delays Beyond Contractor's Control:
Owner understands that there may be delays to beginning and/or completing the project that are beyond
Contractor's control.These include weather, strikes,war, terrorist attacks, shortages in supply or delay in
getting materials, additional labor or subcontractors. In the event of such delay, Owner agrees to modify the
„,, n� , 670 Newfield St Unit C
5-STAR Middletown, CT 06457
RATING ;, (860) 877-3006-Office
0 r
'..
/!Ul1lll CT ID HIC#0651199
U
MA ID HIC#204338
.11°1\ PREFERRED
LA ROOFINGLLC °`vE"s CONTRACTOR
CoR"WCi s
CUSTOMER NAME PHONE DATE
Josh Wherry (816)728-0660 08/29/2023
ADDRESS JOB NAME
187 Prospect Street 2308-4854800-01
CITY STATE ZIP JOB LOCATION
Northampton MA 01060 187 Prospect Street
At your request, we will submit the following : Roof Replacement-PORCHES& LOWER MAIN HOUSE ROOF
ONLY, Repair Items on Main Roof, PVC Composite Wall Flashing/Wall Detailing, Chimney Flashing, Ridge
Vent Replacement, Drip Edge Replacement(included in roof replacement section).
Scope of Work
Preparation
1. Cover all surrounding areas with tarps-for siding and landscaping; taking extra care for any flowerbeds and bay
windows by utilizing plywood to cover-to prevent any damage to the property from debris.
2. Remove all layers of existing roofing down to wood deck on porch areas, sides, front and back AND lower main
house roof.
Installation
3. Nail down any loose plywood and replace any damaged plywood with CDX 1/2”or 5/8" plywood. The first 2 sheets
of plywood (If plywood replacement is necessary)are covered by LA Roofing. If more than 2 sheets need to be
replaced, it will be an additional$100 per sheet.
4.Apply NEW aluminum F5 drip edge and C4 rake edge[White]on all eaves of roof area on house.
5.Apply FULL Owens Corning Ice/Water Barrier on porch roofs per Massachusetts Building Code for low-pitch roof
areas. Install ice/water barrier 6ft up eaves of lower main house roof.
6. Tape all seams of plywood with roofing deck tape.
7. Install synthetic underlayment on remaining exposed decking.
8. Install Owens Corning starter strips on all eaves of roof.
9. Install new Owens Corning, TruDefinition Duration®or Duration Designer°, 50 Year Limited Lifetime Warranty
Commonwealth of Massachusetts
Division of Occupational Licensure
/ Board of Building Re ulations and Standards
Constructit b r Specialty
,J Per P Y
CSSL-106268 z' E,pires: 09/15/2026
COLLETTE SOMA• f
40 HILLSIDE AVE lig
PLANTSVILLE CT 1 .' ! 1 i
. . " , ,
,,,
;i- _
00 ., 1100
----
Commissioner
r
,.,.. C.A,,,GL..:,_
THE COMMONWEALTH OF MASSACHUSETTS
Office of Consumer Affairs and Business Regulation
1000 Washington Street-Suite 710
Boston, Massachusetts 02118
Home Improvement Contractor Registration
Type: LLC
LA ROOFING AND SIDING LLC Registration: 204338
D/B/A LA ROOFING SPECIALISTS Expiration: 02/03/2024
670 NEWFIELD ST
UNIT C
MIDDLETOWN,CT 06457
Update Address and Return Card.
THE COMMONWEALTH OF MASSACHUSETTS
Office of Consumer Affairs&Business Regulation Registration valid for Individual use only before the
expirotioi date. If found return to:
HOME IMPROVEMENT CONTRACTOR
TYPE:LLC Office of Consumer Affairs and Business Regulation
Registration Expiration1000 Washington Street -Suite 710
204338 02/03/2024 Boston,MA 02118
LA ROOFING AND SIDING LLC
0/B/A LA ROOFING SPECIALISTS
LUIS A.POMAQUIZA
40 HILLSIDE AVE ^'�
PLANTSVILEL,CT 06479
Undersecretary Not valid without signature
�.�__ ...