Cooper Additional Window 9-9-22Proposal - Detailed
Sales Rep E-Mail:alukomski@pellasales.com
Pella Window and Door Showroom of West Springfield
West Springfield, MA 01089
69 Ashley Avenue
Sales Rep Name:Lukomski, Adam
Sales Rep Phone:(413) 335-3237
Sales Rep Fax:413-774-6348
Customer Information Project/Delivery Address Order Information
Customer Notes:1 ADDITIONAL WINDOW THAT WAS MISSED ON ORIGINAL ORDER IN UNIT 2A. IN A FURNACE CLOSET AND FACING FIRE ESCAPE ON EXTERIOR.
WILL TRY TO ORDER AS QUICKLY AS POSSIBLE AND INSTALL THIS WINDOW ALONG WITH THE RECOVERY WINDOW IN FIRST FLOOR OFFICE.
Primary Phone:
Mobile Phone:
Fax Number:
E-Mail:
Contact Name:
County:
Owner Name:
Owner Phone:
Order Number:
Quote Number:
Quote Name:
Cust Delivery Date:
Quoted Date:
Order Type:
Payment Terms:
Customer PO #:
Cooper Rich 55 State St Northampton MA Missed 250 DH unit 2A furnace
739
(413) 5630954
Rich Cooper
55 State St
NORTHAMPTON, MA 01060-3010
C.O.D.
Installed Sales
(413) 5630954
Rich Cooper
55 State St
HAMPSHIRE
15970303
9/9/2022
NORTHAMPTON, MA 01060-3010
Booked Date:
None
Lot #
Wall Depth:
Contracted Date:Great Plains #:1006229051
Tax Code:MASS
Customer Number:
Customer Account:1006229051
1010074037
7of1PagePrinted on Detailed Proposal
For more information regarding the finishing, maintenance, service and warranty of all Pella® products, visit the Pella® website at www.pella.com
9/9/2022
Location:
Rough Opening:
Attributes
Viewed From Exterior
Item Price Ext'd Price
Line #
Qty
1
2A Furnace Closet
31" X 61"
Pella 250 Series, Double Hung, 30.5 X 60.5, White
$1,386.92 $1,386.92
50
1: Non-Standard SizeNon-Standard Size Double Hung, Equal
Frame Size:30 1/2 X 60 1/2
General Information:Standard, Vinyl, Block, Foam Insulated, 3 1/4", 3 1/4", Sill Adapter Included, Head Expander Included
Exterior Color / Finish:White
Interior Color / Finish:White
Glass:Insulated Dual Low-E Advanced Low-E Insulating Glass Argon Non High Altitude
Hardware Options:Cam-Action Lock, White, Standard Vent Stop, No Limited Opening Hardware
Screen:Full Screen, InView™
Performance Information:U-Factor 0.27, SHGC 0.25, VLT 0.47, CPD PEL-N-211-00072-00002, Performance Class R, PG 35, Calculated Positive DP
Rating 35, Calculated Negative DP Rating 35, Year Rated 08|11, Clear Opening Width 25.454, Clear Opening Height 24.839, Clear Opening Area 4.390638,
Egress Does not meet typical United States egress, but may comply with local code requirements
Remake:,
Grille:GBG, No Custom Grille, 3/4" Contour, Traditional (3W2H / 3W2H), White, White
Wrapping Information:Pella Recommended Clearance, Perimeter Length = 182".
PK #
2121
PF-3 - Cut back sills and stops (Interior)1Qty
LP-1 - Lead safe practices this opening 1Qty
PF-1 - Interior Pocket Installation 1Qty
Location:
Rough Opening:
Attributes
Viewed From Exterior
Item Price Ext'd Price
Line #
Qty
2
Interior Stops Wood Products 3 1/2 Craftsman 2, Length: 96, Bright White. Wood Type: Pine
$75.52 $151.04
120
1: Accessory
Frame Size:1 X 1
General Information:Pine, 3 1/2 Craftsman 2
Interior Color / Finish: Bright White Paint Interior
Remake:,
Wrapping Information:Perimeter Length = 0".
PK #
2121
Customer:Quote Number: Project Name:Rich Cooper Cooper Rich 55 State St Northampton MA 15970303
7of2PagePrinted on Detailed Proposal
For more information regarding the finishing, maintenance, service and warranty of all Pella® products, visit the Pella® website at www.pella.com
9/9/2022
Customer:Quote Number: Project Name:Rich Cooper Cooper Rich 55 State St Northampton MA 15970303
Location:Attributes
Item Price Ext'd Price
Line #
Qty
1
25% discount to match previous order
($383.31) ($383.31)
125
Thank You For Your Interest In Pella® Products
7of3PagePrinted on Detailed Proposal
For more information regarding the finishing, maintenance, service and warranty of all Pella® products, visit the Pella® website at www.pella.com
9/9/2022
Customer:Quote Number: Project Name:Rich Cooper Cooper Rich 55 State St Northampton MA 15970303
PELLA WARRANTY:
Pella products are covered by Pella's limited warranties in effect at the time of sale. All applicable product warranties are incorporated into and become a part of
this contract. Please see the warranties for complete details, taking special note of the two important notice sections regarding installation of Pella products and
proper management of moisture within the wall system. Neither Pella Corporation nor the Seller will be bound by any other warranty unless specifically set out in
this contract. However, Pella Corporation will not be liable for branch warranties which create obligations in addition to or obligations which are inconsistent with
Pella written warranties.
Clear opening (egress) information does not take into consideration the addition of a Rolscreen [or any other accessory] to the product. You should consult your
local building code to ensure your Pella products meet local egress requirements.
Per the manufacturer’s limited warranty, unfinished mahogany exterior windows and doors must be finished upon receipt prior to installing and refinished annually,
thereafter. Variations in wood grain, color, texture or natural characteristics are not covered under the limited warranty.
INSYNCTIVE PRODUCTS: In addition, Pella Insynctive Products are covered by the Pella Insynctive Products Software License Agreement and Pella Insynctive
Products Privacy Policy in effect at the time of sale, which can be found at Insynctive.pella.com. By installing or using Your Insynctive Products you are
acknowledging the Insynctive Software Agreement and Privacy Policy are part of the terms of sale.
Notice of Collection of Personal Information: We may collect your personal information when you interact with us. Under the California Consumer Privacy Act
(CCPA), California residents have specific rights to request this information, request to delete this information, and opt out of the sharing or sale of this information
to third parties. To learn more about our collection practices and your rights under the CCPA please visit our link https://www.pella.com/california-rights-policy/at
pella.com.
ARBITRATION AND CLASS ACTION WAIVER ("ARBITRATION AGREEMENT")
YOU and Pella and its subsidiaries and the Pella Branded Distributor AGREE TO ARBITRATE DISPUTES ARISING OUT OF OR RELATING TO YOUR
PELLA PRODUCTS (INCLUDES PELLA GOODS AND PELLA SERVICES) AND WAIVE THE RIGHT TO HAVE A COURT OR JURY DECIDE DISPUTES. YOU
WAIVE ALL RIGHTS TO PROCEED AS A MEMBER OR REPRESENTATIVE OF A CLASS ACTION, INCLUDING CLASS ARBITRATION, REGARDING
DISPUTES ARISING OUT OF OR RELATING TO YOUR PELLA PRODUCTS.You may opt out of this Arbitration Agreement by providing notice to Pella no later
than ninety (90) calendar days from the date You purchased or otherwise took ownership of Your Pella Goods. To opt out, You must send notice by e-mail to
pellawebsupport@pella.com , with the subject line: “Arbitration Opt Out” or by calling (877) 473-5527. Opting out of the Arbitration Agreement will not affect the
coverage provided by any applicable limited warranty pertaining to Your Pella Products. For complete information, including the full terms and conditions of this
Arbitration Agreement, which are incorporated herein by reference, please visit www.pella.com/arbitration or e-mail to pellawebsupport@pella.com, with the subject
line: “Arbitration Details” or call (877) 473-5527.D'ARBITRAGE ET RENONCIATION AU RECOURS COLLECTIF ("convention d'arbitrage") EN FRANÇAIS SEE
PELLA.COM/ARBITRATION. DE ARBITRAJE Y RENUNCIA COLECTIVA ("acuerdo de arbitraje") EN ESPAÑOL VER PELLA.COM/ARBITRATION.
Seller shall not be held liable for failure or delay in the performance of its obligations under this Agreement, if such performance is hindered or delayed by the
occurrence of an act or event beyond the Seller’s reasonable control (force majeure event), including but not limited to earthquakes, unusually severe weather and
other Acts of God, fire, strikes and labor unrest, epidemics, riots, war, civil unrest, and government interventions. Seller shall give timely notice of a force majeure
event and take such reasonable action to mitigate the impacts of such an event.
Product Performance Information:
U-Factor, Solar Heat Gain Coefficient (SHGC), and Visible Light Transmittance (VLT) are certified by the National Fenestration Rating Council (NFRC).
7of4PagePrinted on Detailed Proposal
For more information regarding the finishing, maintenance, service and warranty of all Pella® products, visit the Pella® website at www.pella.com
9/9/2022
Customer:Quote Number: Project Name:Rich Cooper Cooper Rich 55 State St Northampton MA 15970303
Manufacturer stipulates that these ratings conform to applicable NFRC procedures for determining whole product performance. NFRC ratings are determined for a
fixed set of environmental conditions and a specific product size. NFRC does not recommend any products and does not warrant the suitability of any product for
any specific use.
Design Pressure (DP), Performance Class, and Performance Grade (PG) are certified by a third party organization, in many cases the Window and Door
Manufacturers Association (WDMA). The certification requires the performance of at least one product of the product line to be tested in accordance with the
applicable performance standards and verified by an independent party. The certification indicates that the product(s) of the product line passed the applicable
tests. The certification does not apply to mulled and/or product combinations unless noted. Actual product results will vary and change over the products life.
For more performance information along with information on Florida Product Approval System (FPAS) Number and Texas Dept. of Insurance (TDI) number go to
www.pella.com/performance.
BRANCH WARRANTY:
Refer to Pella Corporate Warranty
TERMS & CONDITIONS:
HOMEOWNER - FOR YOUR INFORMATION LEGAL CONTRACT REQUIREMENTS FOR HOME IMPROVEMENT CONTRACTORS IS DETAILED BELOW
THIS SITE RESPONSIBILITIES FORM IS PART OF YOUR CONTRACT WITH PELLA PRODUCTS INC.
155 MAIN STREET, GREENFIELD, MA 01301
HOME IMPROVEMENT CONTRACTOR REGISTRATION # 142279 EXP. 3-01-24 FEDERAL TAX ID #: 04-2303271
The law requires the following fourteen items to be included in any contract between the homeowner and a registered home improvement contractor in all contracts for home
improvement work subject to MGL c 142A
1. The complete agreement between the owner and a clear description of any other documents which are part of the agreement.
2. The full names, federal ID, addresses (not PO box #'s) of the parties, the contractor’s registration number, the names(s) of the salesperson(s)) involved, if any and the date the
contract was executed by the parties
3. The date on which the work is scheduled to begin and the date the work is scheduled to be substantially complete.
4. A detailed description of the work to be done and the materials to be used.
5. The total amount agreed to be paid for the work to be performed under the contract.
6. A time schedule of payments to be made under the contract and the amount of each payment stated in dollars, including all finance charges, if any. Any deposit required to be
paid in advance of the start of the work shall not exceed one-third of the total contract price or the actual cost of any material or equipment of a special order or custom-made
nature, which must be ordered in advance of the start of the work to assure that the project will proceed on schedule.
6A. All units are special order from the manufacturer. These units are sized and specified for your specific project. No units are of "stock" nature.
7. All parties must sign the contract.
8. There shall be a clear and conspicuous notice stating:
a. That all Home Improvement Contractors shall be registered and that any inquiries about a contractor or subcontractor relating to a registration should be directed to:
Registration Division, Program Coordinator
One Ashburton Place - Room 1301
Boston, MA 02108
617-727-3200 x 25239
7of5PagePrinted on Detailed Proposal
For more information regarding the finishing, maintenance, service and warranty of all Pella® products, visit the Pella® website at www.pella.com
9/9/2022
Customer:Quote Number: Project Name:Rich Cooper Cooper Rich 55 State St Northampton MA 15970303
b. The contractor’s registration number must be on the first page of the contract.
c. The homeowner’s three-day cancellation rights under MGL c93s48; NGK c 140D s 10or MGL c255D s 14 as may be applicable.
d. All warranties on the owner’s rights under the provisions of 780 CMRR6 and MGL c 142A
e. In ten-point bold type or larger, directly above the space provided for the signature, the following statement:
DO NOT SIGN THIS CONTRACT IF THERE ARE ANY BLANK SPACES
f. Whether any lien or security interest is on the residence as a consequence of the contract
9. An enumeration of such other matters upon which the owner and contractor may lawfully agree.
10. Any other provisions otherwise required by the applicable laws of the Commonwealth
11. Permit Notice: Every contract shall contain a clause informing the owner of the following:
a. and all necessary construction related permits
b. that it shall be the obligation of the contractor to obtain such permits as the owner's agent
c. that the owner who secure their own construction related permits or deal with unregistered contractors shall be excluded from access to the Guarantee Fund.
12. Acceleration of payment: No contract shall contain an acceleration clause under which any part or all of the balance not yet due may be declared due and payable because the
holder deems himself to be insecure. However, where the contractor deems himself to be insecure, he may require as a prerequisite to continuing said work that the balance funds
due under the contract, which are in possession of the owner, shall be placed in a joint escrow account requiring the signatures of the home improvement contractor and the
owner for withdrawal.
13. No work shall begin prior to the signing of the contract and transmittal to the owner of a copy of such contract.
14. Arbitration: If the contractor determines that in the event of a dispute, the contractor wishes the dispute to be settled by arbitration, this fact must be signified on the contract
and both the contractor and owner shall sign this clause separately. The contractor and the homeowner hereby mutually agree in advance that in the event that the contractor has
a dispute concerning this contract, the contractor may submit such dispute to a private arbitration service which has been approved by the Office of Consumer Affairs and
Business Regulation and the consumer shall be required to submit to such arbitration as provided in MGL c 142A
Owner:___________________
Contractor:________________
Notice: The signatures of the parties above apply only to the agreement of the parties to alternate dispute resolution initiated by the contractor. The owner may initiate
alternative dispute resolution even where this section is not signed separately by the parties.
When Pella Products, Inc. is the Builder or Contractor, as defined by the Vermont Residential Energy Standards (RBES) it agrees to meet or exceed the Vermont RBES then in
effect with the products it installs. Unless the customer requests greater energy efficiency targets be met in writing prior to the execution of this contract, Pella Products Inc. will
at its sole discretion determine how to best satisfy the basic RBES then in effect at the time of installation. Pella Products Inc. shall not be responsible for any windows or doors
installed by third parties or the homeowner independently of the Pella Products, Inc. installation and it cannot certify that the project will meet or exceed the RBES when other
parties install windows or doors that do not individually or collectively meet the RBES standards then in effect. The customer agrees to indemnify, defend and hold harmless
Pella Products, Inc. from any and all claims related to the RBES related to windows and doors installed by third party installers or the homeowner.
SERVICE LABOR WARRANTY : The standard Pella Service Warranty applies. Please note that any costs for equipment, scaffolding and safety equipment that is
required to obtain access for large or to inaccessible units will be at cost of homeowner, even if these costs are incurred during the labor warranty period.
This form constitutes a contract between Buyer and Seller. Prices are subject to change any time after 5 days following date of estimate and does not guarantee availability of any
product listed. Pella Products Inc. management has final authority on acceptance of this order. Your signature confirms the accuracy of the product(s) chosen.
7of6PagePrinted on Detailed Proposal
For more information regarding the finishing, maintenance, service and warranty of all Pella® products, visit the Pella® website at www.pella.com
9/9/2022
Customer:Quote Number: Project Name:Rich Cooper Cooper Rich 55 State St Northampton MA 15970303
Order Totals
Taxable Subtotal
Sales Tax @
Non-taxable Subtotal
Total
Deposit Received
Amount Due
$725.65
$429.00
$1,200.00
$0.00
6.25%$45.35
$1,200.00
7of7PagePrinted on Detailed Proposal
For more information regarding the finishing, maintenance, service and warranty of all Pella® products, visit the Pella® website at www.pella.com
9/9/2022