32C-210 (4) *****************************************************************************
Required Notice: Do not sign this contract if there are any blank spaces. This is a legally
binding agreement If there are any provisions which you do not understand, you should
consult with an attorney before signing.
OWNER: Sandra Milo,47 Holyoke Street,Northampton,MA
01 Date: '7
V
CONTRACTOR: Kurtz,Inc., 121 Summit Lock Road,Westfield,MA
Y: Date: ,,
Cr
Home Improvement Contractor Registration No.: f d
Federal ID No. or Social Security No.: n V.;2,
8
` Time is of the essence of this Contract as to both parties hereto.
XVIII. Contract of Record
The provisions of this Agreement shall supersede all other contracts and other written documents
concerning the work described herein.
XIX. Property Protection
The Contractor shall adequately protect the work, the Owner's property and the public and the
Contractor shall be responsible for any damage or injury due to his act or neglect. When adjacent
property is affected or endangered by any work done under this Agreement, it shall be the
responsibility of the Contractor to take, at his expense, whatever steps are necessary for the
protection of the adjacent property, and to notify the Owner thereof of possible hazards.
XX. Insurance
A. The Contractor shall carry or require that there be carried full and complete Workers
Compensation insurance for all of his employees and those of his subcontractors engaged
in work on the contract premises, for not less than the statutory limits or the following,
whichever is greater:
Accident $100,000
Disease Policy Limit $500,000
Disease Each Employee $100,000
B. In addition, the Contractor shall carry Commercial General Liability (CGL) in the
following amounts:
General Aggregate: $1,000,000
Each Occurrence: $500,000
C. Contractor shall also carry Professional Automobile - for owned, non-owned, hired and
leased vehicles, in the following amounts:
Each Occurrence Combined Single Limit $500,000
OR
Bodily Injury - each person $250,000
each accident $500,000
Property damage - each occurrence $100,000
Certificates of such insurance must be presented to Owner at the time the Agreement is signed
by the Contractor. Each policy shall contain a 30-day notice of cancellation, change or non-
renewal. Owner must be named as an additional insured on the CGL policy. The Contractor
and all subcontractors, their servants, agents or employees waive subrogation rights against
Owner for all losses.
XXI. Assignment of the Contract
The Contractor shall not assign this contract without prior written approval of the Owner.
XXII. Miscellaneous
This Agreement shall be construed under the laws of the Commonwealth of Massachusetts and
amended only by written instrument executed by both the Owner and the Contractor.
7
installed or constructed on said property by the Contractor are of good quality and free from
defects in workmanship or materials. Deficiencies, subject to the warranty set forth in this
paragraph, shall apply only to such deficiencies and defects as to which Owner or subsequent
owners shall have given written notice to the Contractor at its principal place of business within
one(1)year from the date of Final Acceptance by the Owner.
XH. Sub-Contractors
A. Contractor agrees that all the warranties contained herein shall apply to all work performed
under the Contract, including that performed by any sub-contractors. Sub-contractors to
supply licenses and Certificate of Insurance verification prior to start of any work.
B. Owner's Right to Assume Rights of Contractor.
Contractor shall require in its contract with each Subcontractor that in the event of any default
by the Contractor under the Subcontract, or in the event of termination of this Contract, after
notice by Owner to Subcontractor of such termination, owner shall have the right but not the
obligation to assume the Contractor's rights and obligations under the Subcontract.
C. Owner's Right to Reject Choice of Subcontractor.
The Contractor shall not contract with a proposed Subcontractor to whom the Owner has
made reasonable and timely objections. Should such an objection be raised by Owner,
Contractor shall propose another Subcontractor to whom Owner has no reasonable objection.
No increase in Contract Sum shall be allowed for such changes unless the Contractor has
acted promptly in submitting names as required.
XIIL Acknowledgment
All warranties herein are in addition to, and not in limitation of, any and all other rights and
remedies to which the Owner or subsequent owners may be entitled, at law or in equity, and shall
survive the conveyance of title, delivery of, possession of the property, or other final settlement
made by the Owner and shall be binding on the undersigned notwithstanding any provision to the
contrary contained in any instrument heretofore or hereinafter executed by the Owner.
XIV. Contingency Amount
Contingency amounts may be used,if needed,only for the following costs:
Payment for extra work and changes as agreed upon in writing per the terms and conditions
above.
XV. Removal of Debris
Upon the completion of the work, Contractor agrees to remove all construction debris and surplus
material from the property and leave the property in a neat and broom clean condition with all
items cleaned and ready for owner's immediate use.
XVI. Lead-Based Paint Product
Lead-based paint products shall not be used, in compliance with federal regulations found at 24
Code of Federal Regulations Part 35.
XVH. Expediency
6
An adjustment shall be made for increases in the cost of performance of the Agreement,
including profit on the increased cost of performance, caused by suspension, delay or
interruption. NO adjustment shall be made to the extent that performance is, was or would
have been so suspended, delayed or interrupted by another cause for which the Contractor is
responsible or that an equitable adjustment is made or denied under another provision of this
Agreement.
VI. Notice of Completion
Owner agrees to sign a Notice of Completion for recording within ten (10) days of satisfactory
completion of the work. Contractor agrees to release the Owner and property from all claims
upon receipt of the completion payment (retention). Certificates of Occupancy which may be
required to permit full use and occupancy shall be secured and paid for by the Contractor and
shall be a condition precedent to substantial completion of the Work.
VII. Change Orders
Owner and Contractor expressly agree that no material changes or alterations in the work, price or
time, as provided above, shall be made unless in writing and agreed to by Owner and Contractor.
No claim for extra compensation or extra time will be allowed on account of Contractor's failure
to properly estimate quantities, materials, cost, location and measurements of all items required to
complete the Work.
VIII. Permits and Codes
Contractor agrees to secure and pay for all necessary permits and licenses required, which are:
and to adhere to applicable local codes
and requiremenW whether or not covered by the Work Write-up and Specifications and any
drawings for the work, including State of Massachusetts contractor registration requirements.
Upon completion of the Work, the Contractor shall deliver the original permits, licenses and
certificates to the Owner.
Required Notice. In the event that the Owner rather than the Contractor obtains the necessary
permits, or if the Contractor is not registered with the Board of Building Regulations, the
Owner will not be entitled to obtain any benefits from the Guarantee Fund established under
Massachusetts General Laws Chapter 142A.
IX. Equal Opportunity
Contractor agrees to provide Equal Opportunity to all persons, without discrimination as to race,
color, creed, religion, national origin, sex, marital status, age, and status with regard to public
assistance or disability.
X. Unacceptable Risk
Contractor represents that at the time of execution hereon Contractor's company is not listed on
the Disbarred and Suspended Contractors list of the U.S. Department of Housing and Urban
Development.
XI. Warranty
For good and valuable consideration, Contractor hereby agrees to provide a full one-year
warranty to the Owner, which shall extend to subsequent owners of the property to be improved.
The warranty shall provide that improvements, hardware and fixtures of whatever kind or nature
5
B. Owner's Right to Carry Out the Work.
If the Contractor defaults or neglects to carry out the Work in accordance with the Contract
Documents whether observed before or after completion of Work, and fails within a seven-
day period after receipt of written notice from the Owner to commence and continue
correction of such default or neglect with diligence and promptness, the Owner may, without
prejudice to other remedies the Owner may have, correct such deficiencies. In such case an
appropriate Change Order shall be issued deducting from payments then or thereafter due the
Contractor, the cost of correcting such deficiencies. If payments then or thereafter due the
Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to
the Owner.
C. Owner's Right to Reject Work.
The Owner shall have the right to reject the Work which does not conform to the Contract
Documents. If the Owner prefers to accept work which is non conforming, the Owner may do
so instead of requiring its correction, in which case the contract will be reduced as appropriate
or equitable. Such adjustment shall be effected whether or not final payment has been made.
D. Termination of the Agreement by Owner for Cause.
If a petition is filed by the Contractor, or against the Contractor with his consent, under any
federal or state law concerning bankruptcy, reorganization, insolvency or relief from
creditors, or if such petition is filed against the Contractor without his consent and is not
dismissed within thirty (30) days, or if the Contractor is generally not paying his debts as they
become due, or if the Contract becomes insolvent, or if the Contractor agrees to the
appointment of a receiver, trustee, liquidator, custodian or the lice of the Contractor or of all
or any substantial portion of its assets, or if a receiver, trustee or liquidator, custodian or the
lice is appointed with respect to the Contractor or takes possession of all or any substantial
potion of its assets or if the Contractor makes an assignment for the benefit of creditors, or if
the Contractor refuses or fails to supply enough properly skilled workers or proper materials,
or if he fails to make prompt payment to any Subcontractor, or for materials or labor in
accordance with the respective s between the Contractor and the Subcontractor, or disregards
laws, ordinances, rules, regulations or orders of any public authority having jurisdiction, or is
otherwise guilty of a violation of any provision of the Contract Documents, the Owner may,
without prejudice to any other right or remedy, after giving the Contractor and his surety, if
any, seven (7) days written notice, terminate the employment of the Contractor and take
possession of the site and of all materials, equipment, tools construction equipment and
machinery thereon owned by Contractor, accept assignment of subcontractors and may finish
the Work by whatever method Owner may deem expedient.
When the Owner terminates the Agreement for any of the reasons stated above, the
Contractor shall not be entitled to receive further payment until the Work is finished.
If the unpaid balance of the Contract Sum exceeds the costs of finishing the Work, including
the Owner's direct and consequential damages as a result of Contractor's default, such excess
shall be paid to the Contractor. If such costs exceed the unpaid balance, the Contractor shall
pay the difference to the Owner. The amount to be paid to the Contractor or Owner, as the
case may be,shall survive termination of the Agreement.
E. Suspension by the Owner for Convenience.
The Owner may, without cause, order the Contractor in writing to suspend, delay or interrupt
the Work in whole or in part for such period of time as the Owner may determine.
4
IV. Start and Completion
Owner is hereby obligated to issue a written Notice to Proceed within ninety (90) days from the date
of acceptance of the Contractor's bid and proposal. If said Notice to Proceed is not received by the
Contractor within this 90 day period, the Contractor shall have the option of withdrawing his bid and
proposal and terminating this Agreement.
Contractor agrees to start work within 10 calendar days after receipt of the written Notice to
Proceed from the Owner and to complete the work on or before ninety days from the date of
the Notice to Proceed.
If completion of the Project is delayed beyond the completion date, and no extension of time is
approved by the Owner, the parties agree that the Owner would suffer damages, but that such
damages would be extremely difficult to ascertain. Therefore, it is agreed that a reasonable
estimate of the damages to be suffered by Owner, in the event that final completion is not
achieved by the date recited, and no extension of time has been approved by the Owner, is Fifty
Dollars($50.00)per day for each day of delay.
If the Contractor fails to complete the work as agreed herein, in addition to receiving $50 for each
day of delay, the Owner may, without prejudice to any other rights or remedies of the Owner,
terminate the Agreement upon seven (7) days written notice, as further provided in Section V(D)
below.
In agreeing to complete the work within the Contract time, Contractor has taken into
consideration and made allowance for ordinary delays and hindrances incident to such work,
whether growing out of delays of common carriers, delays in securing materials or workers,
changes,omissions, alterations,or otherwise.
Excusable delays shall consist of• strikes, lockouts, embargoes, fire, unavoidable casualties,
unusual delays in transportation, national emergency, extraordinary weather conditions, labor and
material shortages which are beyond the reasonable control of Contractor, Owner not allowing
reasonable access to property; provided that the Contractor shall notify the Owner in writing not
later than two (2)days after the initial occurrence of any excusable cause of delay.
If the Contractor is unable to complete any portion of the work due to excusable delay, the
completion date may be extended, provided the extension time period is agreed to, in advance, in
writing by both the Contractor and the Owner.
Contractor agrees it shall have no claim for damages of any kind on account of any delay in
commencement of the Work.
V. Termination of the Contract
A. Owner's Right to Stop Work.
Contractor fails in the Owner's judgment to correct Work which is not in accordance with the
requirements of the Contract Documents or fails, in the Owner's judgment, to carry out Work
in accordance with the Contract Documents, the Owner, by written order signed personally or
by an agent specifically so empowered by the Owner in writing, may order the Contractor to
stop the Work, or any portion thereof, until the cause for such order has been eliminated;
however, the right of the Owner to stop the Work shall not give rise to a duty on the part of
the Owner to exercise this right for the benefit of the Contractor or any other person or entity.
3
hereto and incorporated herein. This represents the entire Agreement between the parties and
supersedes prior negotiations, representations or agreements,either written or oral.
I. Hold Harmless
Contractor shall agree to defend, indemnify, and hold harmless the Owner, from liability and claim
for damages because of bodily injury, death, property damage, sickness, disease or loss and expense
arising from Contractor's Performance under this Agreement to install or construct home
improvements. Contractor is acting in the capacity of an Independent Contractor with respect to the
Owner.
II. Lien Waivers
Contractor agrees to protect, defend and indemnify Owner from any claims for unpaid work, labor
or materials with respect to Contractor's Performance. Final or progress payments shall not be due
until Contractor has delivered to the Owner, complete or partial releases as applicable of all liens for
work completed arising out of Contractor's Performance or receipt in full covering all labor and
materials for which a lien could be filed, or a bond satisfactory to the Owner indemnifying him/her
against any lien. The lien releases shall be provided for all subcontractors as well as for the
Contractor, including all those who have supplied labor, materials or equipment in connection with
the work under this Agreement.
III. Contract Price
The Owner shall pay the Contractor in current funds for the performance of the work, subject to
additions and deductions by Change Order, the Contract Sum of thirteen thousand nine hundred
forty dollars($13,940).
Contractor may make application to the Owner for progress payments as soon as those portions of
the work described in the attached Work Write-up and Specifications have been completed. The
application shall include an invoice describing the work that was performed and the payment
amount requested and releases of any liens as indicated in Section H of this Agreement. Upon
approval of such application by the Owner, the Contractor shall be paid the sum requested, subject
to a 10%retention, which will be paid 35 days after a Certificate of Occupancy is issued.
Applications approved by the last Friday of each calendar month shall be paid before the end of the
following month.
Required Notice. Any deposit required under this Agreement to be paid in advance of the
commencement of work shall not exceed the greater of one-third of the total contract price or the
actual cost of any material or equipment which has to be special ordered or custom made, which
must be ordered in advance of the commencement of the work, in order to assure the project will
proceed on schedule. No final payment may be demanded until the Agreement is completed to
the satisfaction of both Owner and Contractor.
2
HOMEOWNER AND CONTRACTOR AGREEMENT
Required Notice: All residential contractors and subcontractors are required to be registered
with the Massachusetts Board of Building Regulations and Standards, unless specifically
exempt from registration. Inquiries concerning registration should be directed to: Director,
Home Improvement Contractor Registration, One Ashburton Place, Room 1301, Boston, Ma
02108(617) 727-8598.
................................................................................
Required Notice: NOTICE OF CANCELLATION
The Owner may cancel this Contract if it is signed at a place other than the Contractor's
business address, if the Owner notifies the Contractor in writing of his or her intention to do so
not later than midnight of the third business day following the signing of the Contract.
YOU MAY CANCEL THIS AGREEMENT, IF IT HAS BEEN SIGNED BY A PARTY
THERETO AT A PLACE OTHER THAN AN ADDRESS OF THE SELLER, WHICH
MAY BE HIS MAIN OFFICE OR BRANCH THEREOF, PROVIDED YOU NOTIFY
THE SELLER IN WRITING AT HIS MAIN OFFICE OR BRANCH BY ORDINARY
MAIL POSTED, BY TELEGRAM SENT OR BY DELIVERY, NOT LATER THAN
MIDNIGHT OF THE THIRD BUSINESS DAY FOLLOWING THE SIGNING OF THIS
AGREEMENT SEE THE ATTACHED NOTICE OF CANCELLATION FORM FOR
AM LE OF THIS RIGHT.
J Co tract is ignature Owner's Signature
■as■■■■■■■■■■■won■/s o n■was■■///■//////
This Agreement is made this 3 day of 40-1 , 2001, by and between Kurtz, Inc., having
a principal place of business located at 121 Summit Lock Road, Westfield, MA, hereinafter
referred to as "Contractor", and Sandra Milo of 47 Holyoke Street, Northampton, MA, the
Owner of subject property located at 47 Holyoke Street, Northampton, MA, hereinafter referred to
as IlOwner".
WHEREAS the Contractor intends to repair the property located at:
47 Holyoke Street, Northampton,MA.
NOW THEREFORE, the Contractor and Owner, for the considerations hereinafter named agree as
follows:
That this Agreement shall consist of the Contractor's bid and proposal, the general conditions and
references contained herein, the drawings and work write-up, if any, and the specifications attached
1
1
• Bath - 2'-6"X6'-6" hollow care
• Right side room-2'-4"X6'-6" hollow core
Right side room closet - 2'-4"X6'-6" hollow core
YOU are encouraged to start on Wednesday as you have proposed. Please call the homeokvner,
Sandra Milo, at 413-584-5140 to arrange access.
f Call me if you have any questions.
i I I
mere are the proposea cnange oraer Items. r-iease get DacK to me as soon as possiore wan
prices.
• Delete all painting, interior and exterior.
Use a pressure treated 6-X.6 set in concrete for the bottom newel posts on the side porch
stair railing.
• Provide now stairs for the first floor rear entry. Stairs shall be constructed to meet
building code requirements, including rails. All wood shall be pressure treated.
• Provide new stairs for the second floor rear entry. Stairs shall be constructed to meet
building code requirements, including rails. All wood shall be pressure treated. Remove
all existing treads and risers, including lower section. Install new stringers, treads, risers
and rails to code. Construct support for shed corner. Existing roof to remain.
Provide ten f 101 new doors, jambs, casings and hardware for first floor. All doors shall
be molded hardboard six panel. Casings shall be paint grade flat 1X pine. Casings must
extend to existing plaster or plaster must be filled to casings. Wall thickness varies.
Check with homeowner for door swing. Bedroom and bathroom locksets shall be
-77 "bed/bath" privacy locks, two doors off front entry shall be entry locks, keyed alike, other
/ doors matching passage sets. Schlage or equal. Doors are as follows:
Front hall–Two (2) 2'-6"X6'-8"solid core. Include thresholds.;— �v ��p C o fy
f o Living room
s Closet - 2'-6"X6'-8" hollow core
■ Front room -2'-6"X6'-8" hollow core 1 Uj 0(_4�!,
■ Side room - 2'-8"X6'-8"hollow core {'I
o Kitchen
• Left side room - 2'-6"X6'-8" hollow core
• Back room -2'-6"X6'-6"solid core with threshold
Vf Technical Specifications
47 Holyoke St., Northampton, MA
01 GENERAL REQUIREMENTS
010 Summary of the Work
1.1. The "Work" of this contract is defined in the Contract Documents to include, but not
necessarily be limited to, all work by all trades necessary to complete the following
repairs/renovations to 47 Holyoke Street.,Northampton,MA:
1.1.1. MASONRY
1.1.1.1. Reset steps,side and front porches.
1.1.2. CARPENTRY
1.1.2.1. Exterior
1.1.2.1.1.Repair/replace broken/missing roof trim. posts and rail.
1.1.2.1.2.On upstairs side porch: repair rotted floor, p
New rail must allow water to run under.
1.1.2.1.3.On upstairs rear egress porch/stairs, replace rotted floor,
replace worn or damaged treads and install guardrail(handrail
only now).
1.1.2.2. Interior
i 1.1.2.2.1.1n 1st floor living room, repair drop ceiling. I"U ip.
structure above ceiling(sag showing in 2nd floor&roof).
1.1.2.2.2.In Ist floor storage room off kitchen,repair water damage to
floors,ceilings and walls.
1.1.2.2.3.Repair loose tread/threshold on stairs from 2nd floor living
room to kitchen.
1.1.3. THERMAL AND MOISTURE PROTECTION
1.1.3.1. Roofing
1.1.3.1.I.Re-roof low-slope(left lower)roof using double-coverage roll
roofing. Replace or install new flashing at all walls and eaves.
1.1.3.1.2.Repair flashing on rear chimney.
1.1.4. FINISHES 'F c
1.1.4.1. Repaint as required after eleadin
2. All work to be performed in a workmanlike manner accordance with the Massachusetts state
building code, all other applicable federal, state, and local codes and regulations, and accepted
trade practice. Materials to be installed in accordance with manufacturer's recommendations.
3. The Contractor will be responsible for initiating, maintaining, and supervising all safety
precautions and programs necessary for the completion of the work.
011 General
I. USE OF THE PREMISES
1.1. The contractor will have access to the jobsite during normal business hours, Monday
through Saturday. Any work scheduled for off-hours time must be approved by the
Owner.
1.2. The Contractor shall limit his use of the premises for his work and for storage of his
materials.
1.3. The General Contractor for this project shall assume full responsibility for the protection
and safekeeping of all materials for this project.
1.4. The Contractor shall perform all work at the jobsite under the coordination of the
Construction Manager and Owner,in regard to such issues as the following:
1.4.1. Access to the workspace.
1.4.2. Storage of materials at the jobsite.
1.4.3. Parking of Contractor vehicles at the jobsite.
1.4.4. The location of construction debris and dumpsters during the construction
period.
2. INSURANCE
2
Jun 13 01 02: 25p
P- 6
1 . r
p4-�tV W P.-
9 a fiats tlrrtls'
DEPARTMENT OF BUILDM INSPECTIONS
212 Main Street ' Municipal Building
Northampton, Mass. 01060 y
WORI{ER'S COMPENSATION INSURANCE A MI AVIT
L _ _�-e l� vrfiZ
(lic�nstrlpermiaee}
with a principal place of business/resideace art:
av�uov\VV\lf�--��� t►�1 �O Fbone.#)_Q 13 56 9 00<c
(t;tr�i/ci tylstatriz�p)
do hereby certify, under the pains and penalties of perjury, that
team an employer providing the following worker's compensation coverage for my
employees wo�riking on this jab:
(Insurance Company) (Po[icy Mumb r') (Expiration Date)
( ) I azn a sole proprietor, general contractor or homeowner(circle one) and have hired
the contractors listed below who have the following worker's compensation policies:
(Name of Contractor) (Insurance Compaoy/PoUcy Number) (Fxpirntion Date)
(Name of Contractor) (In_su=ce Comparry/Policy Number) (Expiration Date)
(Nacre of Contractor) (Insurance Company/Poficy Number) (Expiration Date)
(Name of Contractor) _(Insurance Company/Mcy Number) (Expiration Date)
(attach additiond shed tf noocnuy to inchtde information perta.ining ton oealracton>
J
( ) I am a sole proprietor and have no one working for me.
( ) I am a home owner performing alt the work myself.
NOTE:please&awart that whist homcouacn who tmPfay personi to do„a .r ,x ooasJ ur_;oa of rzpatir uvrSc on a dwelling of
not mate taw throe units in tohid►the honit*- r rtud=or on fix gfc aa6 zpputtea.x j tivxrn act oot grnaally oonridcted to be
employes undcf the wockr{s cxxz =Ulion Act(GL152,ss 1(5)).awikation by a hoasooaoir far a lictmo a P=Dil may Viderrx the
lco status of as amploy.r under the War$da ca upmsatioa Aru
I uadau*ad thai a copy of this muemaa may be forvewded to tho Depwtnxart of Iadudrial A.O&.&offfoe of Iax'nooe for five
oouesnge VrnfiC160a and that f lure to exult nouettV under seetioa 25A atMGL 1ST can lead to the impexiboa of ui-iW P-Al its
eoasioing of a-fine of up to S 1,500.00 andlor kzpris�of up to one year sad eavil pcvatties in the form of a stop Wort Or+--and a
tint o(5100-00 a day tpiust tna
For dcpatmet�l wo onty
Permit Number
map# Lot
Jun 13 01 02: 24p
P. 5
� ..., r.
81 Licensed Construction Supervisor: Not Applicable ❑
lf-Name of License Holder: U--.r C—
License N iser
Address U Expiration Date
q 13�
Signature Telephone
Not Applicable ❑
U V— C
Comoan Name Re istration Numl5er
Fox; 1397 WTSI-fiQU- - / 6-15-97 (3- 19 - 6
ddre s l Expiration Date
elephone 36
'Pt KEitSQMPEfi75AT1QNNS;UI2AI4FF13)A11.T(M G L.c"132, 513{6j)
Workers Compensation Insurance affidavit must be completed and submitted with this application. Failure to provide this affida
will result in the denial of the issuance of thp building permit.
Signed Affidavit Attached Yes._..... No...... ❑
The current exemption for"homeowners"was extended to include Owner-occupied Dweliines of one(1) or to o(2)familie:
and to allow such homeowner to engage an individual for hire who does not possess a license,provided that the owner acts
as supervisor.CMR 780, Sixth Edition Section 108.3.5.1.
Definition of Homeowner:Person(s)who own a parcel of land on which he/she resides or intends to reside,on which there
is,or is intended to be,a one or two family dwelling,attached or detached structures accessory to such use and/or farm
structures.Aperson who constructs more than one home in a two-year period shall not be considered a homeowner.
Such"homeowner"shall submit to the Building Official,on a form acceptable to the Building Official,that he/she shall be
responsible for all such work yerformed under the buildine permit.
As acting Construction Supervisor your presence on the job site will be required from time to time,during and upon
completion of the work for which this permit is issued.
Also be advised that with reference to Chapter 152(Workers'Compensation) and Chapter 153(Liability of Employers to
Employees for injuries not resulting in Heath)of the Massachusetts General Laws Annotated,you may be liable for person(s
you hire to perform work for you under this permit.
The undersigned"homeowner"certifies and assumes responsibility for compliance with the State Building Code,City of
Northampton Ordinances,State and Local Zoning Laws and State of Massachusetts General Laws Annotated.
Homeowner Signature
Jun 13 01 02:24p
- .,
New House ❑ Addition ❑ Replacement Windows Alterations)i Roofing
Or Doors
Accessory Bldg. ❑ DernolitionO New Signs ( J pecks [ ] Siding[ ] Other 4 ]
Brief Description of Proposed Work: ( g_,Y> r �;r �/krtii� 1c l`0,� -f�
Alteration of existing droom Yes No Adding new bedroom Yes _�No
Attached Narrative Renovating unfinished basement Yes -__-ZNo
Plans Attached Roll D- Sheet a
a. Use of building:One Family Two Family Other
b. Number of rooms in each family unit: Number of Bathrooms
c. Is there a garage attached?
d. Proposed Square footage of new construction. Dimensions_
e. Number of stories?
f. Method of heating? Fireplaces or Woodstoves Number of each
g. Energy Conservation Compliance. — Mascheck Energy Compliance form attached?
h. Type of construction
i. Is construction within 100 ft.of wetlands?--Yes No, Is construction within 100 yr. floodplain__—Yes I`
j. Depth of basement or cellar floor below finished grade _
k. Will building conform to the Building and Zoning regulations? Yes_ No.
I. Septic Tank City Sewer Private well City water Supply
- - _
as Owner of the subject propert
hereby authorize _ to act
my behalf, in all matters relative to work authorized by this building permit application.
signature of Owner Date
t, as Owner/Authorized Agent
hereby declare that the statements and information on the foregoing application are true and accurate, to the best of my
knowledge and belief.
Signed under the pains and penalties of perjury.
Print Nam
Signatur f 4 r/Agent 4 N Date
Jun 13 01 02:23p
p. 3
3 _
Section 4.
ALL INFORMATION MUST BE COMPLETED, or PERMIT CAN BE
DENIED DUE TO LACK OF INFORMATION
Existing Proposed Required by Zoning
This column to be filled in by
Building Department
Lot Size
Frontage
Setbacks Front
Side L: R: L: R:
Rear
Building Height
Bldg.Square Footage
Open Space Footage %
{Lot area minus bldg&paved
Arkin
if of Parking Spaces
Fill:
volume&Location)
A. Has a Special Permit/Variance/Finding ever been issued for/on the site?
NO DON'T KNOW YES
IF YES, date issued:
IF YES: Was the permit recorded at the Registry of Deeds?
NO DON'T KNOW YES
IF YES: enter Book _ Page and/or Document#
B. Does the site contain a brook, body of water or wetlands? NO DON'T KNOW
YES
IF YES, has a permit been or need to be obtained from the Conservation Commission?
Needs to be obtained Obtained Date Issued:
C. Do any signs exist on the property? YES _ _ NO
IF YES, describe size, type and location;
D. Are there any proposed changes to or additions of signs intended for the property ?YES —
No
IF YES, describe size, type and location:
Jun 13 01 02: 23p
P. 2
DQ Wit mpton
Buildin rtment
JUN 2001 R l OOeet
Northam ton, A 01060
DEPT j0dtmMk 240 ax 413.587.1272
NORTHAMPTON,MA 01060
APPLICATION TO CONSTRUCT,ALTER, REPAIR, RENOVATE OR DEMOLISH A ONE OR TWO FAMILY DWELLING
SEC7'�t3N 3 •S!•`TE�NfO�NfA�+IO�V. (�- � '� � V
11 Property Address: z -
VoKg-
ElSt. lS1YJC,f�` ':�
Ar e
SfCT4Q 2-PROPERTY 1P/AUTHOTTZ D.AtGENT
2.1 Owner of Record:
Name(Print) Current Mailing A _reTSS-2 C ��
3-i-- tfJ
Signature
2.2 Authorized Agent:
V f,w
Name(Print) Current Mailing Address:
Signature Telephone
Item Estimated Cost(Doiiars)to be -Use Dnly
completed by ermit applicant
1- Building (a}Building Permit Pee
2. Electrical (b)Estimated Total Cost of
Construction 6
3, Plumbing Building Permit Fee
4. Mechanical(HVAC)
5. Fire Protection ----
6. Total =(2 + 2 + 3 +4 + 5) O . ( U Check Number 7
ihis-Sccticin,F-or Official Use.Onl
1sg Permtt LVumber "•t o2 bate Issued: r
F BurldLrig Cq rrsiP. taloi !` 4+$ a .
File#BP-2001-1072
APPLICANT/CONTACT PERSON KURTZ INCORPORATED
ADDRESS/PHONE P O BOX 1597 (413)568-0636
PROPERTY LOCATION 47 HOLYOKE ST
MAP 32C PARCEL 210 ZONE URC
THIS SECTION FOR OFFICIAL USE ONLY:
PERMIT APPLICATION CHECKLIST
ZONING FORM FILLED OUT ENCLOSED REQUIRED DATE
Fee Paid
Building Permit Filled out
Fee Paid
Typeof Construction: REPLACE INTERIOR DOORS ROLLED ROOF &EXTERIOR STAIRCASES
New Construction
Non Structural interior renovations
Addition to Existing
Accessory Structure
Build_ine Plans Included:
Owner/Statement or License 036505
3 sets of Plans/Plot Plan
THE LLOWING ACTION HAS BEEN TAKEN ON THIS APPLICATION:
Approved as presented/based on information presented.
Denied as presented:
Special Permit and/or Site Plan Required under: §
PLANNING BOARD ZONING BOARD
Received&Recorded at Registry of Deeds Proof Enclosed
Finding Required under: § w/ZONING BOARD OF APPEALS
Received&Recorded at Registry of Deeds Proof Enclosed
Variance Required under: § w/ZONING BOARD OF APPEALS
Received&Recorded at Registry of Deeds Proof Enclosed
Other Permits Required:
Curb Cut from DPW Water Availability Sewer Availability
Septic Approval Board of Health Well Water Potability Board of Health
Permit from Conse ion Commission Permit from CB Architecture Committee
00A 01 oe
LO 20 0
Signature of Building Official Date
Note: Issuance of a Zoning permit does not relieve a applicant's burden to comply with all zoning
requirements and obtain all required permits from Board of Health,Conservation Commission,Department
of public works and other applicable permit granting authorities.
7 HOLCQKE S'I~ a BP-2001-1072
GIs#: COMMONWEALTH OF MASSACHUSETTS
21i> '" CITY OF NORTHAMPTON
Lot: -001
Permit: Building
Category:Non structural interior renovations BUILDING PERMIT
Permit# BP-2001-1072
Project# JS-2001-1892
Est.Cost: $13940.00
Fee: $69.00 PERMISSION IS HEREBY GRANTED TO:
Const.Class: Contractor: License:
Use Group: KURTZ INCORPORATED 036505
Lot Size(sq. ft.): 3179.88 Owner: MILO SANDRA J
Zoning URC Applicant: KURTZ INCORPORATED
AT: 47 HOLYOKE ST
Applicant Address: Phone: Insurance:
P O BOX 1597 (413) 568-0636 Workers
Compensation
WESTFIELDMA01086 ISSUED ON.6/20/01 0:00:00
TO PERFORM THE FOLLOWING WORK.-REPLACE INTERIOR DOORS, ROLLED ROOF, &
EXTERIOR STAIRCASES
POST THIS CARD SO IT IS VISIBLE FROM THE STREET
Inspector of Plumbing Inspector of Wiring D.P.W. Inspector of Buildings
Underground: Service: Meter:
Footings:
Rough: Rough: House# Foundation:
Final: Final:
Rough Frame:
Gas Fire Department Fireplace/Chimney:
Rough: Oil: Insulation:
Final: Smoke: Final:
THIS PERMIT MAY BE REVOKED BY THE CITY OF NORTHAMPTON UPON VIOLATION OF
ANY OF ITS RULES AND REGULATIONS.
Certificate of Occupancy Sienature:
Fee Type: Receipt No: Date Paid: Check No: Amount:
Building 6/20/010:00:00 12433 $69.00
212 Main Street,Phone(413)587-1240,Fax: (413)587-1272
Building Commissioner-Anthony Patillo